HomeMy WebLinkAboutRESOLUTION NO. 2023-78RESOLUTION NO. 2023-78
RESOLUTION AUTHORIZING A PROFESSIONAL SERVICES
AGREEMENT BETWEEN THE CITY OF FAIRFAX AND HALL AND
HALL ENGINEERS, INC.
WHEREAS, the Fairfax City Council intends to complete planning services with the
objective to establish a new annexation boundary with the City of Cedar Rapids, gain an
understanding of how the City of Cedar Rapids will meet the water supply needs of the Big Cedar
Industrial Center and how this may impact the City of Fairfax's water supply source, and establish
some form of agreement or understanding that protects the City of Fairfax's water supply source
now and in the future; and
WHEREAS, as part of this project the Fairfax City Council also intends to complete a
desktop hydrogeological Assessment to gain a better understanding of how the City of Cedar
Rapids water supply to the Big Cedar Industrial Center may impact the City of Fairfax's water
supply source; and
WHEREAS, Hall and Hall Engineers, Inc. has submitted a Professional Services
Agreement to provide planning services and a desktop hydrogeological Assessment to assist the
City of Fairfax in obtaining these objectives.
NOW, THEREFORE, BE IT RESOLVED, by the City Council of the City of Fairfax,
Iowa, to enter into this Professional Services Agreement with Hall and Hall Engineers, Inc. as
attached.
BE IT FURTHER RESOLVED, by the City Council of the City of Fairfax, Iowa, that
the Mayor and City Clerk are hereby authorized and directed to execute both this Resolution and
the Professional Services Agreement.
Passed and approved this 1 lth day of July, 2023.
AYES: Nurre, Daly, Pacha, Volk, and Wainwright
NAYS: None
��7�� e�
Jo Ann Beer, Mayor
ATTEST:
g';4 ,i�' , �- `,�'��..
;
Cy hia Stimson, City Clerk/Treasurer
4.^ .
, ,.
:, , � �,
,, ,
�� x . ,.,
;:�'
Planning Services to Establish a New Annexation Boundary & Assessment of Possible Impacts to the City's Water Supply Source
HHE Project No. 6950-23-02
SHQRT FORM OF AGREEMENT
BETWEEN OWNER AND ENGINEER
FOR
PROFESSIONAL SERVICES
THIS IS AN AGREEMENT effective as of Jt� 1 I. 20�3 ("Effective Date") between City of Fairfa�+ ("Owner"} and
C �all & }-1a11_Lngineers, Inc. (`Bngineer").
Owner's Projcct, of which Engineer's services under this Agreement are a part, is generally identified as follows:
Iowa Land & Building Company (Alliant Energy) is annexing land that is part of the Big Cedar Industrial Center to
the City of Cedar Rapids that is located on the City of Fairfax side of the 2001 (28E) Sanitary Sewer Services and
Annexation Boundary Agreement. As part of this process, it is the City of Fairfax's understanding that Alliant Energy
is pursuing industries to locate on this land (the land to be annexed into the City of Cedar Rapids) that will require up
to 15 million gallons of water per day, and possibly more. 1t is also the City of Fairfax's undcrstanding that to address
some or all of thase water supply needs, the City of Cedar Rapids may drill wells to the Silurian aquifer, which is the
same water source the City of Fairfax utilizes for the City's water supply needs. As a part of these services, the
Engineer shall:
1. Work with the City nfCed�r Rapids to establish a new {28�) Annexation Boundary & Annexation Boundary
Agreement between the two Cities;
2. Work with the City of Cedar Rapids to establish a clear understanding of how the water supply needs of the
Cedar Rapids portion of the Big Cedar Industrial Center will be met, and identify possible impacts that this
may have on the City of Fairfax's water supply source (Silurian Aquifer).
3. Work with the City of Cedar Rapids, and other entities as necessary to establish some form of agreement or
nnderstanding that protects the City of Fairfax's water supply source (Silurian Aquifer) now and in the future.
There shall be two phases to this project, which are as follows:
A. Hall and Hall Engineers planning services, which shail include the following:
a. Meetings & Coordination with City Staff/ Personnel, Attorney hired by the City of Fairfax, City of Cedar
Rapids personnel, City Development Board and Staff, Alliant Energy Personnel, and other Personnel &
Organizations that may be necessary to complete this project;
b. Prepare necessary Exhibits;
c. Coordinate with and review the report / study and Tnvoicing from iSG / LRE;
d. Bxpenses such as mileage, Towa I7NR Eees, postage, printing, etc.
B. Desktop Hydrogeologic Assessment by ISG, Inc. and LRE Water, which shail include the following:
a. Prepare a base map showing the City's existing and proposed wells, and the proposed hypothetical well
field for the Big Cedar Industrial Center Project;
b. Confrm the proposed target rates for the City's wells and the Big Cedar Industrial Center Project well
field;
c. Estimate & map the theoretical drawdown and assess the well interference on the City's wells from the
Big Cedar Industriai Center Project well field using a standard analytical model (i.e., Cooper-Jacob).
Assume 24-hour, 7-day, and 1-year pumping scenarios.
d. Prepare a technical Memorandum that summarizes the results, provides a level of risk to the City's future
use of the Silurian Aquifer, and recommendations for additiottal work, if needed, and yuestions for the
Projeot Stakeholders.
EJCDC E-520 Short Form of Agreement Behveen Owner and Engineer for Professional Services.
Copyright �2009 Vallonal Society oFProfessional Engineers Tar F,.ICDC. All �ights reserved.
Paee 1
Planning Services to Establish a New Annexation Boundary & Assessment of Possible Impacts to the City's Water Supply Source
HHE Project No. 6950-23-02
Owner and Engineer further agree as follows:
1.01 Basic Agreement and Period of Service
A. Engineer shall provide, or cause to be provided, the services set forth in this Agreement. If authorized by
Owner, or if required because of changes in the Project, Engineer shall furnish services in addition to those
set forth above. Owner shall pay Engineer for its services as set forth in Paragraphs 7.01 and 7.02.
B. Engineer shall complete its services within a reasonable time, or within the following specific time period;
• A. Planning Services: June 1, 2023 — Unknown
• B. Desktop Hydrogeologic Assessment: July, 2023 — September, 2023
C. If the Project includes construction-related professional services, then Engineer's time for completion of
services is conditioned on the time for Owner and its contractors to complete construction not exceeding ??
znonths. If the actual time to complete construction exceeds the number of months indicated, then Engineer's
period of service and its total compensation shall be appropriately adjusted.
2.01 Payment Procedures
A. Invoices: Engineer shall prepare invoices in accordance with its standard invoicing practices and submit the
invoices to Owner on a monthly basis. Invoices are due and payable within 30 days of receipt. If Owner fails
to make any payment due Engineer for services and expenses within 30 days after receipt of Engineer's
invoice, then the amounts due �ngineer will be increased at the rate of 1.0% per month (or the maximum rate
of interest permitted by law, if less) from said thirtieth day. In addition, Engineer may, after giving seven days
written notice to Owner, suspend services under this Agreernent until Engineer has been paid in full all
amounts due for services, expenses, and olher related charges. Owner waives any and all claims against
Engineer for any such suspension. Payrnents will be credited first to interest and then to principal.
3.Q1 Termination
A. The obligatinn to continue performance under this Agreement may be terminated:
1. For cause,
a. By either party upon 30 days written notice in the event of substantial failure by the other party
to perform in accordance with the Agreement's terms through no fau(t of the terminating party.
Failure to pay Engineer for its services is a substantial failure to perform and a basis for
termination.
b. By Engineer:
1} upon seven days written notice if Owner demands that Engineer furnish or perform services
contrary to Engineer's responsibiiities as a licensed professional; or
2) upon seven days written notice if the Engineer's services for the Project are delayed for more
than 90 days for reasons beyond Engineer's control.
EJCDC E-520 Short Form of Agreement Between Owner and Engineer for Professional Services.
Copyright C4'�2009 NaHonat Sociely of Professional Engineers for EJCDC. Ait rights reserved.
Paee 2
Planning Services to Establish a New Annexation Boundary & Assessment of Possible Impacts to the City's Water Supply Source
HHE Project No. 6950-23-02
Engineer shalt have no (iability to Owner on account of a termination by Engineer under
Paragraph 3.O1.A.l.b.
c. Nolwithstanding the foregoing, this Agreement will not terminate as a result of a substantial
faiture under Paragraph 3.O1.A. l.a if the party receiving such notice begins, within seven days of
receipt of such notice, to correct its substantial failure to perform and proceeds diligently to cure
such failure within no more than 30 days of receipt of notice; provided, however, that if and to
the extent such substantial failure cannot be reasonably cured within such 30 day period, and if
such party has diligently attempted to cure the same and thereafter continues diligently to cure
the same, theii the cure period provided for herein shall extend up to, but in no case more than,
60 days after the date of receipt of the notice.
2. For convenience, by Owner effective upon Engineer's receipt of written notice from Owner.
B. The terminating party under Paragraph 3.O 1.A may set the effective date oftermination at a time up to 30 days
later than otherwise provided to ailow Engineer to complete tasks whose value would otherwise be lost, to
prepare notes as to the status of completed and uncompleted tasks, and ta assemble Project materials in orderly
files.
C. In the event of any termination under Paragraph 3.01, Engineer will be entitled to invoice Owner and to receive
full payment for all services performed or furnished in accordance with this Agreement and all reimbursable
expenses incurred through the effective date of termination.
4.01 Successors, Assigns, and Beneficiaries
A. Owner and Engineer are hereby bound and the successors, executors, administrators, and legal representatives
of Owner and Engineer (and to the extent permiited by Paragraph 4,O 1.B the assigns of Owner and Engineer)
are hereby bound to the other party to this Agreement and to the successors, eaecutors, administrators, and
legal representatives (and said assigns) of such other party, in respect of all covenants, agreements, and
obligations of this Agreement.
B. Neither Owner nor Engineer may assign, sublet, or transfer any rights under or interest (including, but without
limitation, moneys that are due or may become due) in this Agreement without the written consent of the
other, except to the extent that any assignment, subletting, or transfer is mandated or restricted by law. Unless
specifically stated to the contrary in any written consent to an assignment, no assignment will release or
discharge the assignor from any duty or responsibility under this Agreement.
C. Unless cxpressly provided otherwise, nothing in this Agreement shall be construed to create, impose, or give
rise to any duty owed by Owner or Engineer to any contractor, subcontractor, supplier, other individual or
entiiy, or to any surety for or employee of any of them. All duties and responsibilities undertaken pursuant to
this Agreement will be for the sole and exclusive benefit of Owner and Engineer and not for the benefit of
any other party.
5.01 General Considerations
A. The standard of care for all professional engineering and related services performed or furnished by Engineer
under this Agreement will be the care and skill ordinarily used by members of the subject profession practicing
under similar circumstances at the same time and in the same locality, Engineer makes no warranties, express
or implied, under this Agreement or otherwise, in connection with Engineer's services. Subject to the
foregoing standard of care, Engineer and its consultants may use or rely upon design elements and information
EJCDC E-520 Short Form of Agreement Between Owner and Engineer for Professionai Services.
Copyright �2009 National Society of ProPessional Engineers ['or EJCDC. All rights reserved.
� Pagc 3
Planning Services to Establish a New Annexation Boundary & Assessment of Possible Impacts to the City's Water Supply 5ource
HHE Project No. 6950-23-02
ordinarily or customarily furnished by others, including, but not limited to, specialty contractors,
manufacturers, suppliers, and the publishers of technical standards.
B. Engineer shall not at any time supervise, direct, control, or have authority over any contractor's work, nor shall
Engineer have authority over or be responsible for the means, methods, techniques, sequences, or procedures
of construction selected or used by any contractor, or the safety precautions and pragrams incident thereto,
for security or safety at the Project site, nor for any failure of a contractor to comply with laws and regulations
applicable to such contractor's furnishing and performing of its work.
C. This Agreement is to be governed by the law of the state or jurisdiction in which the Project is located.
D. Engineer neither guarantees the performance of any contractor nor assumes responsibility for any contractor's
failure to furnish and perform its work in accordance with the contract between Owner and such contractor.
Engineer is not responsible for variations between actual construction bids or costs and Engineer's opinions
or estimates regarding construction costs.
�. Engineer shall not be responsible for the acts or omissions of any contractor, subcontractor, or supplier, or of
any of their agents or employees or of any other persons (except Engineer's own employees) at the Project
site or otherwise furnishing or performing any canstruction work; or for any decision made regarding the
construction contract requirements, or any application, interpretation, or clarification of the construction
contract other than those made by Engineer.
F. The general conditions for any construction contract documents prepared hereunder are to be the "Standard
General Conditions of the Construction Contract" as prepared by the Engineers Joint Contract Documents
Committee (EJCDC G700, 2007 Edition) unless the parties agree otherwise.
G. All documents prepared or furnished by En�ineer are instruments of service, and Engineer retains an
ownership and property interest (including the copyright aad the right of reuse) in such documents, whether
or not the Project is completed. Owner shall have a limited license to use the documents on the Project,
extensions of the Project, and for related uses of the Owner, subject to receipt by Engineer of full payrr►ent for
ail services relating to preparation of the documents and subject to the following limitations: (1) Owner
acknowledges that such documents are not intended or represented to be suitable for use on the Project unless
completed by Engineer, or for use or reuse by Owner or others on extensions of the Project, on any other
project, or for any other use or purpose, without written verification or adaptation by Engineer; (2) any such
use or reuse, or any modification of the documents, without written verification, completion, or adaptation by
Engineer, as appropriate for the specific purpose intended, will be at Owner's sole risk and without liability
or legal axposure to Engineer or to its officers, directors, members, partners, agents, employees, and
consultants; (3) Owner shall indemnify and hold harmtess Engineer and its officers, directors, members,
partners, agents, employees, and consultants from all claims, damages, losses, and expenses, including
attorneys' fees, arising out of or resulting from any use, reuse, or modification of the docurnents without
written verification, completion, or adaptation by Engineer; and (4) such limited license to Owner shall not
create any rights in third parties.
H, To the fullest extent permitted by law, Owner and Engineer (1) waive against each other, and the other's
employees, officers, directors, agents, insurers, partners, and consultants, any and all claims for or entitlement
to special, incidental, indirect, or consequential dam.ages arising out of, resulting from, or in any way related
to the Project, and (2) agee that Engineer's total liability to Owner under this Agreement slaall be limited to
$50,000 or the total amount of compensation received by Engineer, whichever is greater.
EJCDC E-520 Short Form of Agreement Between Owner and Engineer for Professional Serviccs.
Copyright �20(19 National 5ociety of Professional Engineers for EJCDC. All rights reserved.
1'�fic 4
Planning Services to Establish a New Annexation Boundary & Assessment of Possible Tmpacts to the City's Water Suppty Source
' HHE Project No. 6950-23-02
The parties acknowledge that Engineer's scope of services does not include any services related to a
Hazardous Environmental Condition (the presence of asbestos, PCBs, petroleum, hazardous substances or
waste as defined by the Comprehensive Environmental Response, Compensation and Liability Act, 42 U.S.C.
§§9601 et seq., or radioactive materials). If Engineer or any other party encounters a Hazardous
Environrnental Condition, Engineer may, al its option and without liabitity for consequential or any other
damages, suspend performance of services on the portion of the Project affected thereby until Owner: (1)
retains appropriate specialist consultants or contractors to identify and, as appropriate, abate, remediate, or
remove the Hazardous Environmental Condition; and (2) warrants that the Site is in full compliance with
applicable Laws and Regulations.
Owner and Engineer agree to negotiate each dispute between them in good faith during the 30 days after
notice of dispute. If negotiations are unsuccessful in resolving the dispute, then the dispute shall be mediated.
If inediation is unsuccessful, then the parties may exercise their rights at law.
6.01 Total Agreemenl
A. This Agreement (including any expressly incorporated attachments), constitutes the entire agreement between
Owner and Engineer and supersedes all prior written or oral understandings. This Agreement tnay only be
amended, supplemented, modified, ar canceled by a duly executed written instrument.
7.01 Basis of Payment--Cost Plus to a mcrximum, unless otherwise noted below
A. Using the procedures set forth in Paragraph 2.01, Owner shall pay Engineer as follows:
SERVICE
_ _ _ ____
FEE
A. Plannin Services** Cost Plus
B. Deskto H dro eolo ic Assessment*** $12,500.00
Estimated Ex enses*
TOTAL: Cost Plus
*The Expenses are included as part ofA. Planning Services.
** Because this project is unique, and there is not a clear or standard Scope / Tasks to be completed as part
of the A. Planning Servicesportion of thisproject, the Fee for the Planning Services shall be Cost Plus without
a maximum fee specrfied.
*** The Fee for B. Desktop Hyc�i•���reologzc Assessment portion of this project shall be Cost Plus to a
Mcx�rimum Fee of $12, 500. 00.
1. Engineer's Standard Hourly Rates are attached as Appendix 1
2. Owner to pay all fees and expenses for the project with no mark up. Fees may include Vehicle
Mileage, Iowa DNR Fees, Publication fees, and mailing fees.
HHE shall sub-consult with ISG, Inc. & LRE Water on this project. The ISG, Inc. & LRE Water
sub-consultant fees are the B. Desktop Hydrogeologic Assessment portion of this project.
7.02 Additional Services: For additional services of �ngineer's employees engaged directly on the Project, Owner
shall pay Engineer an amount equal to the cumulative hours charged to the Project by each class of Engineer's
EJCDC E-5Z0 Shurt Form of Agreemeni Between Owner and Engineer for Professional Services.
Copyright 002009 NaHonal Society of Professional Engineers for EdCDC. All rights reserved.
['�e� 5
Planning Services to Establish a New Annexation Boundary & Assessment of Possible Impacts to the City's Water Supply Source
HHE Project No. 6950-23-02
employees times standard hourly rates for each applicable billing class; plus reimbursable expenses and
Engineer's consultants' charges, if any. Engineer's standard hourly rates are attached as Appendix 1.
The following Services are NOT included as part of the Scope of Services of this Agreement, and are
considered Additional Services above and beyond the Scope and Schedule as provided for in this Agreement:
Attachments: Appendix l, Engineer's Standard Hourly Rates; Appendix 2, Special Provisions; Attachment
1, Anticipated Project Schedule.
IN WI'TI�IESS WHEREOF, the parties hereto have executed this Agreement, the Effective Date of which is
indicated on page 1.
O WNER: ENGINEER: '
. � �.�%
By: Jo Ann Beer ��,��,��. ,����, By:
Title: Mayor
Date Signed: `!� l� � �
Address for giving notices:
Title: Public Team Leader
Date Signed:
Engineer Liceuse or Firm's Certificate
Number: 421308857
State of Iowa
Address for giving notices:
City of Fairfax, Iowa Hall & Hall Engineers Inc.
300 80�` Stree# Court, P.O. Box 337 1860 Boyson Road
Fairfax, IA 52228 Hiawatha IA 52233
EJCDC E-S7A Short Form of Agreement Between Owner and Engineer for Profess[onal Services.
Copyright 02009 Nationai 5ociety of Professional Engineers for EJCDC. All righta reserved.
I'�ge 6
Planning Services to Establish a New Annexation Boundary & Assessment of Possible Impacts to the City's
Water Supply Source
HHE Ptoject No. 6950-23-02
This is Appendix 1, Engineer's
Standard Hourly Rates, referred to in
and part of the Short Form of Agreement
between Owner and Engineer for
Professional Services dated Jttly l l, 2C)23
En�ineer's Standard Hourly Rates
', A. Standard Hourly Rates.
1. Standard Hourly Rates are set forth in this Appendix 1 and include salaries
and wages paid to personnel in each billing class plus the cost of customary
' and statutory benefits, general and administrative overhead, non-project
' operating costs, and operating margin or profit.
2. The Standard Hourly Rates apply only as specified in Paragraphs 7.01 and
7.02, and are subject to annual review and adjustment.
B. Hourly rates for services performed on or afler the Effective Date are.•
POSITION � LEVEL
T II III
Team Leader $145/hour $150/hour $160/hour
ProjectManager � $135/hour $140/hour $150/hour
Associate Team Leader �� $110/hour $120/hour $13 5/hour
Pro'ect Coordinator $90/hour $105/hour $120/hour
Froject Engineer $115/hour $120/hour $135/hour
Design Engineer $100/hour $105/hour $11 S/hour
Civil En ineerin Technician $90/hour $100/hour $110/hour
Proj ect Landscape Architect $115/hour $120/hour $135/hour
Des�n Landscape Architect $100/hour $105/hour $115/hour
Landsca e Architect Technician $90/hour $100/hour $110/hour
Project Surveyor $130/hour $135/hour $145/�►our
Lead Field Surve or $110/hour $120/hour $130/hour
Desi n Surve oy r���_ $85/hour $105/hour $120/hour
Field Surve or $95/hour ------------ ---------- —
Construction Administrator $115/hour $130/hour $140/hour
Construction Observer $90/hour $105/hour $12Q/hour
Administrator � $75/hour $90/hour $145/hour
Intern $55/hour $65/hour ------------
Aerial Field Surveyor � $135/hour
Aerial Data Processing �� $130lhour
Ex ert Witness $200/hour
Traffic Data Collector $95/hour for staff &$50lhour for intern
Mileage — Personal Vehicle $0.66/mile
Milea e_-_C_ompany Truck $0.87/mile
', Appendix 2, Special Provisions
' EJCDC E-520 Short Form of Agreement Between Owner and EnRineer for Professional Services.
' Copyright �2009 National Society of Profeasional Engineere Por EJCDC. All rights reserved.
1'aec 1
Planning Services to Establish a New Annexation Boundary & Assessment of Possible Impacts to the City's
Water Supply Source
HHE Project No. 6950-23-02
This is Appendix 2, Special Provisians,
referred to in and part of the Short Form of
Agreement between Owner and Engineer for
Professional Services dated .1�1y l 1, 2023
Speciat Provisions to this Agreement
Modify paragraph 2.OlA as follows:
Invoices: Engineer shall prepare invoices in accordance with its standard invoicing
practices and submit the invoices to Owner on a monthly basis. Invoices are due and
payable within 30 days of receipt. Accounts unpaid 60 days after the invoice date
may be subject to a monthiy service charge of 1.5% {or the maximum rate of interest
permitted by law, if less). If any portion or all of an account remains unpaid 90 days
after the invoice date, the Owner shall pay all costs of collection, including reasonable
attorney's fees and said accounts may be assigned to a credit agency, be the basis of
mechanics liens, or any and all other debt collection remedies available. In addition,
Engineer may, after giving seven days written notice to Owner, suspend services
under this Agreement until Engineer has been paid in full all amounts due for
services, expenses, and other related charges. Owner waives any and all claims
against Engineer for any such suspension. Payments will be credited first to interest
and then to principal. Invoices paid be credit card will be charged an additional4%
service charge.
Additional Terms and Conditions
Access to Site: Unless otherwise stated, the Engineer will have access to the site for
activities, but has not included in the fee the cost of restoration of any resulting damage.
Informatron Provicled By Others: Owner shall furnish at the Owner's expense, all
information, requirements, reports, data, surveys and instructions required by this
Agreement. The Engineer may use such information, requirements, reports, data, surveys
and instructions in performing its services and is entitled to rely upon the accuracy and
completeness thereof. The F,ngineer shall not be held responsible for any errors or
omissions that may arise as a result of erroneous or incomplete information provided by
the Owner and/or the Owner's consultants and contractors.
Hazardous Materials: The Owner agrees, notwithstanding any other provision of this
Agreement, to the fullest extent permitted by law, to indemnify and hold harmless the
Engineer and its sub-consultants from and against any and all claims, suits, demands,
liabilities, Iosses, damages or costs, including reasonable attorneys' fees and defense
costs arising out of or in any way connected with the detection, presence, handling,
removal, abatement, or disposal of any hazardous or toxic substances, products or
materials that exist on, about or adjacent to the Project site, whether liability arises under
breach of contract or warranty, tort, including negligenee, strict liability or statutory
Appendix 2, Special Provisions
EJCDC E-520 Short Form of Agreement Between Owner and Engineer for Professional Services.
Copyright �2009 National Society of Professional Engineers for EJCDC. All rights reserved.
Paee 2
Planning Services to Establish a New Annexation Boundary & Assessment of Possible Impacts to the City's
Water Supply Source
HHE Project No. 6950-23-02
liability, regulatory or any other cause of action, except for the sole negligence or willful
misconduct of the Engineer.
Certifications, Guarantees and Warranties: The Engineer shall not be required to
execute any document that would result in its certifying, guaranteeing or warranting the
existence of conditions whose existence the Engineer cannot ascertain.
Fzduciary Responsibility: The Engineer shall not offer any fiduciary service to the Owner
and no fiduciary responsibility shall be owed to the Owner by the Engineer or any of its
sub-consultants, as a consequence of the Engineer entering into this Agreement with the
Owner.
Opinions of Probable Construction Cost.• In providin� opinions of probable construction
cost, the Owner understands that the Engineer has no control over the cost or availability
of labor, equipment or materials, or over market conditions or the rnethod of pricing, and
that the �ngineer's opinions of probable construction costs are made on the basis of the
Engineer's professional judgment and experience. The Engineer makes no warraniy,
express or implied, that the bids or the negotiated cost of Project construction will not
vary frnm the Engineer's opinion of prnbable construction cost.
Ualidity of Pricing for Services: The scope, schedule and compensation listed for
services in this Agreement shall be valid for 30 days from the date �ngineer has signed
the agreement. Scope, schedule and compensation are subject to change after the above
30 days have expired.
Mutual Tndemnification
The Engineer agrees, to the fullest extent permitted by law, to indemnify and hold
harmless the Owner, its officers, directors and employees against damages arising
directly from the Engineer's negligent performance of the services under this Agreement
and that of its sub-consultants or anyone for whorn the Engineer is legally liable.
Notwithstanding the foregoing agreement to indemnify and hold harmless, the parlies
expressly agree that Engineer has no duTy to defend the Owner from and against any
claims, causes of actian, or proceedings of any kind.
The Owner agrees, to the fullest extent permitted by law, to indemnify and hold harmless
the Enginecr, its officers, directors and employees against damages arising directly from
the Owner's negligence of the services under this Agreement and that of its contractors,
subcontractors or consultants or anyone for whom the Owner is legally liable.
Notwithstanding the foregoing agreement to indemnify and hold harmless, the parties
expressly agree that Owner has no duty to defend the Engineer from and against any
claims, causes of action, or proceedings of any kind.
Neither the Owner nor Engineer shall be obligated.to indemnify the other pariy in any
manner whatsoever for the other party's own negligence or the negligence of others.
Appendix 2, Special Provisions
EJCDC E-520 Short Form oPAgreement Between Owner and Engineer for Professional Services.
Copyright �2009 National Society of Professional Engineers for EJCDC. All rights reserved.
P�ar 3
Planning Services to Establish a New Annexation Boundary & Assessment of Possible Impacts to the City's
Water Supply Source
HHE Project No. 6950-23-d2
Clarification to the Definition of Engineer
For the purposes of this Agreement, services provided by the Engineer may include land
surveying, landscape architecture, and environmental services in addition to civil
engineering.
Clarificatian to the Definition of Owner
For the purposes of this Agreement, the Owner may be a general contractor, sub-
contractor, individual, corporation, non-profit, consultant, and any other type of entity
for which the Engineer is providing services.
Electronic Data. Release
' The owner exercises the right to request that the Engineer provide a copy of their
' electronic survey, design and/or data file(s) pertaining to this project. Said electronic
iile(s) may be preliminary and may not be complete or in final form and shall not be
' intended for construction use. Owner's use or reuse, reproduction, dissemination, and/or
' review (both internally and externally) shall be at the Owner's risk and full legal
' responsibiliiy. Owner shall be fully and solely responsible for reconciling of said
' electronic files with iinal certiiied hard copies produced by the Engineer. Only the final
certified hard copies of the survey, design and/or data files shall be the official plans and
' documents for the project.
By signing this agreement, the Owner does hereby agree to indemnify and hold the
Engineer, it's manager(s), member(s), officers, agents and employees harmless from any
claims, suits, damages; liability, demands or cnsts, including attorney fees resultin� from
or arising out of the use or misuse of said electronic survey, design and/or data file(s) by
' Owner. In the event of suit for breach and/or enforcement of this agreement, Owner
', agrees to pay all attorney fees incurred by Engineer.
The Engineer retains ownership and a property interest in all electronic data prepared to
complete the Engineer's services, including AutoCAD Drawing files ("CAD
Data"). Upon Owner's request for CAD Data and signing Engineer's release form,
Engineer will furnish CAD Data to Owner or others designated by the Owner. CAD
Data will include two-dimensional horizontal line data needed to establish horizontal
alignments and controi. The furnished data, along with control points, elevations and
grades shown on Engineer's plans can be used by others for construction
SUTVEy5. Engineer will not provide construction survey support to others using
Engineer's CAD Data.
Appendix 2, Special Provisions
EJCDC E-520 Short Form of A�reement Behveen Owner and Eagineer for Professional Services.
Copyright �2009 National Society of Professionat Engineers for EJCDC. All rights reserved.
1'Agc 4